89-003368RP
Gte Telephone Operations vs.
Department Of Transportation
Status: Closed
DOAH Final Order on Thursday, March 8, 1990.
DOAH Final Order on Thursday, March 8, 1990.
1STATE OF FLORIDA
4DIVISION OF ADMINISTRATIVE HEARINGS
8GTE FLORIDA, INC., )
12)
13Petitioner, )
15)
16vs. ) CASE NO. 89-3368RP
21)
22DEPARTMENT OF TRANSPORTATION, )
26)
27Respondent. )
29_________________________________)
30FLORIDA POWER AND LIGHT COMPANY, )
36)
37Petitioner, )
39)
40vs. ) CASE NO. 89-3567RP
45)
46DEPARTMENT OF TRANSPORTATION, )
50)
51Respondent. )
53_________________________________)
54SOUTHERN BELL TELEPHONE AND )
59TELEGRAPH COMPANY, )
62)
63Petitioner, )
65)
66vs. ) CASE NO. 89-3570RP
71)
72DEPARTMENT OF TRANSPORTATION, )
76)
77Respondent. )
79_________________________________)
80UNITED TELEPHONE COMPANY, )
84)
85Petitioner, )
87)
88vs. ) CASE NO. 89-3572RP
93)
94DEPARTMENT OF TRANSPORTATION, )
98)
99Respondent. )
101_________________________________)
102FLORIDA NATURAL GAS ASSOCIATION, )
107)
108)
109Petitioner, )
111)
112vs. ) CASE NO. 89-3577RP
117)
118DEPARTMENT OF TRANSPORTATION, )
122)
123Respondent. )
125_________________________________)
126FINAL ORDER
128Pursuant to notice, the above-styled matter was heard before the Division
139of Administrative Hearings ) by its duly designated Hearing Officer, Daniel M.
151Kilbride, on November 2 and 3, 1989, and by stipulation on January 29, 1990, in
166Tallahassee, Florida. The following appearances were entered:
173APPEARANCES
174For Petitioner Lorin H. Albeck, Esquire
180GTE FLORIDA, General Attorney
184INC., GTE Florida Incorporated
188Post Office Box 110, Mail Code 7
195Tampa, Florida
197For Petitioner Jean G. Howard, Esquire
203Florida Power Law Department
207and Light Co. Florida Power and Light
214Company
215Post Office Box 029100
219Miami, Florida
221For Petitioner Robert G. Beatty, Esquire
227Southern Bell Southern Bell Telephone
232Telephone and Legal Department
236Telegraph Co. Museum Tower, Suite 1910
242150 West Flagler Street
246Miami, Florida
248For Petitioner Kay L. Wolf, Esquire
254United Telephone Assistant Vice President-
259Company Law
261United Telephone Company
264of Florida
266Post Office Box 5000
270Altamonte Springs, Florida
273For Petitioner Richard Brightman, Esquire
278Florida Natural Post Office Box 6526
284Gas Association Tallahassee, Florida
288For Respondent Robert P. Daniti, Esquire
294Senior Litigation Attorney
297Department of Transportation
300605 Suwannee Street
303Tallahassee, Florida
305STATEMENT OF THE ISSUES
309Whether Respondent's proposed Rule 14-46.0011 is an invalid exercise of
319delegated legislative authority.
322Whether paragraph 12 of the revised DOT utility permit, incorporated by
333reference in the proposed amendments to Rule 14- 46.001, Florida Administrative
344Code, is an invalid exercise of delegated legislative authority.
353Whether paragraph 15 of the revised DOT utility permit, incorporated by
364reference in the proposed amendments to Rule 14- 46.001, Florida Administrative
375Code, is an invalid exercise of delegated legislative authority.
384Whether the economic impact statement prepared by DOT was inadequate so as
396to amount to an invalid exercise of delegated legislative authority.
406PRELIMINARY STATEMENT
408By notice in the Florida Administrative Weekly, Volume 15, Number 24, June
42016, 1989, the Florida Department of Transportation (DOT) initiated Section
430120.54 rulemaking proceedings to amend Rule 14-46.001, Florida Administrative
439Code, including a revised Utility Accommodation Guide (UAG) which is
449incorporated by reference. The revised UAG supersedes the 1979 edition which is
461incorporated by reference in Rule 14-15.014, which will be repealed. The notice
473also initiates rulemaking proceedings for proposed Rule 14-46.0011. Rule 14-
48346.001(3) requires utilities to obtain permits for use of DOT's right of way.
496The permit is to be issued in conformance with DOT's UAG. The revised UAG
510contains the revised Utility Permit (Permit) which is the subject of this rule
523challenge. In initiating rulemaking, the DOT filed with the appropriate
533agencies the documentation required by the applicable procedural rules at this
544stage of the rulemaking proceeding. The notice contains a summary of the
556estimated impact of the proposed amendments and provides for a public hearing.
568The subject of the proposed amendments is DOT's policies regulating the
579accommodation of utility facilities on public roads and rights of way under DOT
592jurisdiction, including the location and manner of installing, adjusting or
602relocating these facilities. The revised UAG contains the reVised Utility
612Permit which is the primary subject of this rule challenge proceeding.
623Five petitions to invalidate have been consolidated for hearing by order
634dated July 10, 1989. At the October 24, 1989 motion hearing, the undersigned
647granted the DOT and Florida Power and Light Company (FPL) motions for summary
660final order regarding the validity of proposed Rule 14-46.0011. That rule will
672be addressed in this order.
677At the October 24, 1989 motion hearing, the undersigned also granted DOT's
689motion for partial abeyance of all issues raised by each Petitioner, except as
702stated in the issues section of these findings of fact. At the beginning of the
717final hearing, the undersigned also abated Florida Natural Gas Association's
727(FNGA) issue concerning the sufficiency of DOT's notice of incorporation by
738reference of the revised Utility Accommodation Guide. Jurisdiction over the
748abated issues is relinquished to the DOT to the extent necessary to resolve
761these issues through formally announced and noticed changes to the proposed
772rule.
773Petitioner Southern Bell Telephone and Telegraph Company's (Southern Bell)
782Motion in Limine is denied. See: Buy-Low Save Centers, Inc. v. Glinert, 547
795So.2d 1283 (Fla. 4th DCA 1989).
801On November 2, 1989, the formal hearing commenced. Petitioners GTE Florida,
812Inc. (GTE) and FNGA did not present any evidence. Petitioner FPL presented
824three witnesses: Terry Vogel, a fact witness employed by FPL as a division
837relocation coordinator and permit administrator; Dennis LaBelle, an expert in
847the relocation of electric utilities; and Paul LaPointe, an expert in public
859utility accounting.
861Petitioner FPL introduced 19 exhibits which were received into evidence,
871subject to DOT's objections as to relevancy and materiality as noted in the
884transcript. Petitioner Southern Bell introduced eight exhibits, including the
893Affidavit of an expert economic and financial consultant. These exhibits were
904admitted into evidence, subject to DOT's objections as to relevancy and
915materiality as noted in Southern Bell's stipulation with DOT. Petitioner United
926Telephone Company of Florida (UTF) presented five exhibits which were admitted,
937subject to DOT'S objections as to relevancy and materiality pursuant to UTF's
949stipulation with DOT. Respondent DOT presented the testimony of Robert D.
960Buser, P.E.; DOT Director of Construction; and Robert I. Scanlan, DOT Deputy
972General Counsel; together with Exhibits 1 through 9 and 13, which were admitted
985into evidence. The transcript of the hearing on November 2 and 3 was filed with
1000the Clerk of the Division on December 4, 1989. As a result of stipulations by
1015the parties, the need for a third day of hearing was obviated, and the
1029evidentiary record as defined by Section 120.57(1)(a)6., Florida Statutes, was
1039closed on January 29, 1990. By the amended order dated February 2, 1990, the
1053parties were afforded an opportunity to present written proposed findings of
1064fact, conclusions of law and argument of counsel by February 20, 1990, in which
1078Petitioners GTE, FPL and Southern Bell and Respondent have submitted proposals.
1089UTC joined in the proposals submitted by Petitioners. Each have been carefully
1101considered and are addressed in the Appendix.
1108Based upon all of the evidence, the following findings of fact are
1120determined:
1121FINDINGS OF FACT
11241. Respondent, Florida Department of Transportation (DOT), an agency of
1134the State of Florida, was created. and defined pursuant to Section 20.23,
1146Florida Statutes, for the purposes delineated in that section, including the
1157building and maintaining of public transportation facilities.
11642. Petitioner, GTE Florida, Inc. (GTE), is a foreign corporation
1174authorized to do business and doing business in the State of Florida. The
1187company operates a telephone system in this State and, therefore, is regulated
1199by the Florida Public Service Commission, pursuant to Chapter 364, Florida
1210Statutes.
12113. Petitioner, Florida Power and Light Company (FPL) is a Florida
1222corporation and operates an electrical generating, transmission and distribution
1231system in this State and, therefore, is regulated by the Florida Public Service
1244Commission pursuant to Chapter 366, Florida Statutes.
12514. Petitioner, Southern Bell Telephone and Telegraph Company (Southern
1260Bell) is a foreign corporation authorized to do business and doing business in
1273the State of Florida. The company operates a telephone system in this State
1286and, therefore, is regulated by the Florida Public Service Commission pursuant
1297to Chapter 364, Florida Statutes.
13025. Petitioner, United Telephone Company of Florida (UTC) is a Florida
1313corporation. The company operates a telephone system in this State and,
1324therefore, is regulated by the Florida Public Service Commission pursuant to
1335Chapter 364, Florida Statutes.
13396. Petitioner Florida Natural Gas Association (FNGA) is a Florida
1349corporation. FNGA is a trade association whose members are in the business of
1362providing natural gas utility services in Florida.
13697. All Petitioners are substantially affected persons who have standing to
1380initiate this rule challenge proceeding.
13858. By notice in the Florida Administrative Weekly, Volume 15, Number 24,
1397June 16, 1989, DOT initiated Section 120.54 rulemaking proceedings to amend Rule
140914-46.001, including a revised Utility Accommodation Guide (UAG). The revised
1419UAG supersedes the 1979 edition which DOT had incorporated by reference in Rule
143214-15.014, which will be repealed. The notice also initiates rulemaking
1442proceedings for proposed Rule 14- 46.0011.
14489. In initiating rulemaking, the DOT filed with the appropriate agencies
1459the documentation required by the applicable procedural rules at this stage of
1471the rulemaking proceeding. The notice contained a summary of the estimated
1482economic impact of the proposed amendments and provides for a public hearing.
149410. The subject of the proposed amendments is DOT's policies regulating
1505the accommodation of utility facilities on public roads and rights of way under
1518DOT's jurisdiction, including the location and manner of installing, adjusting
1528or relocating these facilities.
153211. Proposed Rule 14-46.0011 challenged by FPL provides:
154014-46.0011 Utilities Liaison. Recognizing
1544that all utility owners serving the public
1551have a common obligation to provide their
1558services in cost effective manner, the
1564Department will coordinate its advance
1569planning of highway projects with the
1575affected utilities to facilitate the
1580relocation of the utility in order to
1587eliminate costly construction delays. As
1592part of the project planning and
1598process the Department will consider the cost
1605of utility work necessary for the proposed
1612project. The Department will keep utility
1618agencies informed of future transportation
1623projects and request the utility agencies to
1630advise the Department of the location of
1637existing and proposed structures within
1642proposed project corridors.
164512. This entire section (14-46.0011) is new and is a statement of policy
1658direction. It announces DOT's determination to coordinate the advance planning
1668of highway projects with affected utilities; to consider the cost of utility
1680work necessary for a proposed project; and to keep utilities informed of future
1693transportation projects. As such, DOT is free to refine this policy and to
1706develop procedures to implement this rule on a case by case basis.
171813. All Petitioners challenge paragraphs 12 and 15 of the amended Utility
1730Permit form which appears at pages 36 and 37 of the UAG.
174214. The new paragraph 12 of the Utility Permit provides:
175212. It is agreed that in the event
1760the relocation of said utility facilities
1766are scheduled to be done simultaneously
1772with the Department's construction work,
1777the permittee will coordinate with the
1783Department before proceeding, shall
1787cooperate with the Department's
1791contractor to arrange the sequence of
1797work so as not to unnecessarily delay the
1805work of the Department's contractor,
1810defend any legal claims of the
1816Department's contractor due to delays
1821caused by the permittee's failure
1826comply with the approved schedule, and
1832shall comply with all provisions of the
1839law and Rule 14-46, Florida
1844Administrative Code. The Permittee shall
1849not be responsible for delays beyond its
1856normal control.
185815. The new paragraph 15 of the Utility Permit provides:
186815. Permittee convenants and agrees
1873that it will indemnify and hold harmless
1880Department and all of Department's
1885officers, agents, and employees from any
1891claim, loss damage, cost, charge or
1897expense arising out of any act, action,
1904neglect or omission by Permittee during
1910the performance of the contract, whether
1916direct or indirect, and whether to
1922person or property to which Department or
1929said parties may be subject, except that
1936neither Permittee nor any of its
1942subcontractors will be liable under this
1948section for damages arising out of
1954or damage to persons or property directly
1961caused or resulting from the sole
1967negligence of Department or any of its
1974officers, agents or employees.
197816. Public utilities are on DOT right-of-way by permit and statutory
1989invitation. Frequently such utilities increase the cost to DOT for
1999accomplishing its mission. These costs include expanded liability for DOT.
200917. DOT has a separate utilities section that reports to the director of
2022construction who is responsible for coordinating, in an orderly manner, the
2033permitting of utilities on the right of way. This includes adjustments
2044necessary because of new construction or improvements to existing roads.
205418. Prior to 1987, the DOT was criticized by the Legislature and the
2067public for delays in completing road construction projects.
207519. The DOT formed a DOT Quality Improvement Team to study utility delays.
2088The DOT team identified the root causes of DOT's problems with utility
2100relocation delays and the DOT practices and procedures. Time delays caused by
2112utilities constituted more than 17% of the total time extensions the DOT granted
2125on road work. However, approximately one-half of utility-caused time delays
2135were due to water and sewer utilities.
214220. The DOT team further determined that the majority of the utility delay
2155claims were located in one area. Of 425 delay claims statewide, only 27 were
2169utility related. Of the 27 utility related claims, 14 were in DOT District I,
2183and 11 of the claims came out of one office within that District. Twelve of the
219914 claims involved city or county utilities. After study and analysis of these
2212facts, the DOT Team came up with solutions to help reduce utility delays. These
2226solutions did not include the provisions of paragraphs 12 and 15 of the Utility
2240Permit.
224121. The DOT sends the utility a set of plans at the 60% and 90% completion
2257stage. Usually the utility would submit a relocation schedule to DOT after it
2270receives the 90% plans. In the DOT's District NO. 1, where most of the problems
2285are, DOT sends the 60% and 90% plans together, so the utility is submitting a
2300relocation schedule based on DOT plans, the utility gives DOT its "approved
2312schedule," the estimate of the number of days that the utility will need in the
2327field to relocate the utility facilities. The estimate is usually tied to the
2340start of the DOT construction, e.g., the utility estimates that it will need 60
2354days in the field after starting of construction to relocate its facilities.
236622. In DOT District 1, there is an average of four utilities involved on
2380all road projects. Each utility files its own schedule with the DOT, and that
2394schedule becomes part of the contract which the DOT signs with the contractor.
2407DOT construction plans can change before construction starts. There can be a
2419delay of as much as two or three years after the utility submits its relocation
2434schedule and the start of the DOT construction.
244223. Prior to the study, each individual utility would submit its own
2454relocation schedule months, sometimes years, before the construction actually
2463begins. An average of four different utilities are involved in a DOT relocation
2476project at the same time. The project schedule did not coordinate the work of
2490the utilities with that of the DOT contractor, resulting in delays to the
2503project.
250424. As a consequence of delays (other than for weather), including delays
2516attributable to utilities, contractors file delay claims. Frequently delay
2525claims are approved which increase the cost of road construction projects for
2537DOT.
253825. The increased costs stem from the amount of time the DOT contractor is
2552forced by the delays, such as delays attributable to utilities, to exceed the
2565contract time. These costs are the cost of labor, equipment, other resources
2577and overhead which the contractor experiences when it does not finish the
2589project on time.
259226. Any delay in road construction work, including time delays caused by a
2605utility's failure to comply with its DOT approved relocation schedule, presents
2616significant disks to the safety of the traveling public and construction workers
2628on the extended job since the construction zone is a hazard6us area. By
2641reducing delays, DOT reduces the exposure of the public and the workers, thereby
2654limiting safety risks. These risks include drop-offs, barricades, lane changes,
2664and other road abnormalities that motorists endure when they drive through a
2676road construction project.
267927. As a result of its study of utility-related time delays to its road
2693construction projects, DOT implemented the several recommendations it had made
2703in its study of time delays.
270928. One recommendation was to require any utilities affected by a road
2721construction project to submit to DOT a detailed schedule of the utility's part
2734of that project. DOT implemented this recommendation in September 1987, and
2745this is now an ongoing DOT policy and practice.
275429. Under the new procedures, where utilities are involved in a DOT road
2767construction project, DOT requires the utilities to develop a schedule for
2778relocating or installing their facilities. The DOT now involves the utilities
2789at every stage of its road construction. Not only does DOT involve utilities at
2803an early stage in the planning of the project, but it also gets the contractor
2818and the utility to confer to reconcile their schedules at a preconstruction
2830conference so that the road construction can proceed in an orderly fashion with
2843utilities being relocated in a manner least disruptive to the job.
285430. The relocation or installation schedule developed by utilities is
2864incorporated by the road contractor in its master schedule for the road
2876construction and is approved by the district construction engineer, resident
2886engineer or project engineer when the job is let for bidding.
289731. The utilities agreement forms the basis for DOT's contract with its
2909road contractor so that the contractor knows what effect the utility will have
2922on the project, with the aim that all parties work together in a coordinated
2936fashion to get the road built.
294232. Since utility time delays were one factor contributing to time delays
2954in DOT road construction, DOT rationally chose to address all facets of the time
2968delay problem, including utility-caused time delays. However, the claims
2977tracking reports upon which DOT relied in determining the need for proposed rule
2990changes do not reflect any reduction in delay claims from the new liaison
3003procedure since it was not implemented at the time of DOT's claims reports.
301633. As a further outgrowth of its study of road construction time delays,
3029DOT determined that the addition of a defense to delay claim provision in the
3043utility permit would increase utilities' compliance with their relocation or
3053installation schedule.
305534. DOT relied upon its claims tracking report as a source of data about
3069the cost to DOT for utility-caused delay claims to support this new permit
3082provision.
308335. While the dollar amounts attributable to settled road contractor delay
3094claims caused by utility time delays are often less than the initial amounts
3107claimed by the contractors, the cost to DOT is a significant total.
311936. The DOT has a policy and procedure for the direct review, processing
3132and resolution of all categories of road contractor claims against DOT and has a
3146specific procedure for processing contractor delay claims attributable to
3155utility delays.
315737. Proposed Paragraph 12 of the Utility Permit will have limited impact
3169with respect to the utility schedules and there is limited connection between
3181paragraph 12 of the permit and reducing contractor delay claims.
319138. The requirement that the utility defend any legal claims of DOT's
3203contractor due to delays caused by the utility's failure to comply with the
3216approved schedule is likely to result in increased litigation and expense for
3228DOT and the Utility.
323239. The DOT utilizes the phrase in paragraph 12 of the Utility Permit:
"3245The permittee shall not be responsible for delays beyond its normal control" in
3258the same way it grants its road contractors extensions of time for circumstances
3271beyond the control of the contractor. This determination is an issue of fact
3284which can be made by the DOT district construction engineer on a case by case
3299basis, following general guidelines developed by the DOT.
330740. The DOT's intent in including the defense requirement in paragraph 12
3319of the Permit is to give DOT "extra clout" with which to threaten the utility
3334with revocation of the Permit if the utility refuses to defend DOT or fails to
3349comply with the schedule.
335341. DOT's recently adopted practice and procedure for processing delay
3363claims and for determining whether a utility should defend DOT from a delay
3376claim attributable to utility delays, provides written notice to the utility and
3388contains extensive levels of review by the DOT professionals involved in the
3400particular road project. If the road contractor's claim of utility delay is not
3413deemed valid, DOT will not require the utility to defend against the claim.
342642. The majority of Petitioner FPL's facilities are not covered by the
3438Permit, in that the facilities are not installed on DOT right-of-way or were
3451installed on DOT right-of- way under the old permit which did not have this
3465provision.
346643. Petitioner Utilities cooperate with DOT in utility relocations, and
3476the utility relocation is a complex process in which there will be projects on
3490which there are problems.
349444. The DOT intends that both paragraphs 12 and 15 of the revised utility
3508permit also become part of its standard form contract for utility installation
3520or relocation, so that the contract mirrors these permit provisions.
353045. The DOT's utility contract or agreement is a separate document,
3541distinct from the DOT utility permit.
354746. The purpose of the permit process is the grant or denial of utility
3561access to DOT's right-of-way and to ensure utility compliance with DOT rules.
357347. The purpose of the DOT utility agreement is to negotiate the time
3586within which a utility must complete its relocation or installation on the DOT
3599right-of-way and provide specific provisions relating to the particular job
3609embraced by the agreement.
361348. The DOT currently requires any utility which seeks to be accommodated
3625on DOT right-of-way to indemnify DOT as follows:
3633a) The existing Utility Permit provides:
363915. It is understood and agreed that the
3647rights and privileges herein set out are
3654granted only to the extent of thin State's
3662right, title and interest in the land to be
3671entered upon and used by the holder, and the
3680holder will, at all times, assume all risk of
3689and indemnify, defend, and save harmless the
3696State of Florida and the Department from and
3704against any and all loss, damage, cost or
3712expense arising in any manner on account of
3720the exercise or attempted exercises by said
3727holder for the aforesaid rights and
3733privileges.
3734b) Master Agreements and project specific agreements with DOT contain
3744provisions resembling the existing paragraph 15 of the utility permit.
3754c) The Master Agreement states:
37592. The COMPANY further agrees that said
3766adjustment, changes or relocation of
3771facilities will be made by the COMPANY with
3779sufficient promptness so as to cause no delay
3787to the DEPARTMENT or its contractor in the
3795prosecution of such construction or
3800reconstruction work; provided, however, that
3805the COMPANY shall not be responsible for
3812delay beyond its control; and that such
"3819Relocation Work" will be done under the
3826direction of the DEPARTMENT'S engineer; and
3832the COMPANY further agrees that in the event
3840the changes, adjustments or relocation of
3846such facilities or utilities are bone
3852simultaneously with the construction project,
3857that it will be directly responsible for the
3865handling of any legal claims that the
3872contractor may initiate due to delays caused
3879by the COMPANY'S negligence; and that the
3886COMPANY will not either proceed with the
"3893Relocation Work" with its own forces or
3900advertise or let a contract for such Work
3908until it has received the DEPARTMENT'S
3914written authority to proceed.
391849. Only a small percentage (6%) of Petitioner FPL utility facilities are
3930on DOT right-of-way, and this percentage will remain constant in the future
3942because of FPL's design philosophy.
394750. Since DOT's utility permit is not required for utility facilities
3958unless the facilities are on the right-of-way, nor for existing facilities not
3970being relocated, the challenged paragraphs of the revised utility permit will
3981not impact a vast majority (94%) of Petitioner FPL facilities.
399151. Utility relocation within DOT right-of-way is at the utility's
4001expense; but if the relocation is from private property to the right-of-way it
4014is at DOT's expense.
401852. For both types of relocations, DOT requires the utility to indemnify
4030and to defend DOT for the utility's own negligence.
403953. The utility is not a party to the contract between the DOT and the
4054road contractor. The control of the DOT contract, contractor and relocation
4065procedures is with the DOT.
407054. Utility relocation schedules do not require work to commence on a
4082calendar date, but rather references definable markers in the progress of the
4094road work.
409655. The DOT did not intend paragraph 12 to require a utility to defend a
4111vehicle owner against claims of the DOT road contractor.
412056. DOT's utility coordinator alerts the utility as to the commencement of
4132the utility's deadline for completing its schedule, and the preconstruction
4142conference also provides the utility with information and guidance.
415157. The DOT road construction plans show all utilities on the project and
4164the location of their facilities.
416958. Proposed paragraph 15 requires a utility, as a condition of its
4181permit, to indemnify the DOT for any act or omission of the utility under its
4196contract (with DOT) to install or relocate utility facilities in the right-of-
4208way, except where the DOT is the sole negligent party.
421859. Since 1984, the DOT has required its construction contractors to
4229indemnify DOT for everything, except for DOT's sole negligence, through a
4240supplemental specification practically identical with proposed paragraph 15.
424860. The indemnification provision of paragraph 15 of the Permit requires
4259as a condition of use of DOT right-of-way that the utility pay for the DOT's
4274joint negligence. This will lessen DOT's exposure to liability and free up more
4287dollars for DOT to spend on roads.
429461. As an example, under paragraph 15 of the Permit, if there were a
4308judgment that DOT was 99% negligent and the utility was 1% negligent, the
4321utility would have to pay the entire judgment under the proposed indemnification
4333clause.
433462. The control of road design and maintenance is with DOT.
434563. DOT intends proposed paragraph 15 to pertain only to tort liability,
4357and the utility must indemnify DOT for DOT's joint liability and not the joint
4371liability of any other person or entity.
437864. Utility installations on DOT right-of-way raise land use issues
4388relating to adequate and efficient use of land which include: (a) reduced
4400overall cost of DOT road improvements; (b) the private landowner's property is
4412not encumbered by utility facilities, which are installed in the DOT right-of-
4424way; (c) less clearing of trees or other vegetation is needed if facilities are
4438installed on the DOT right-of-way; and (d) efficiency of land use is maximized.
4451The utility in some instances has no choice but to put its facilities on public
4466right-of-way. In cases involving building setbacks or road crossings, the
4476utility must obtain a permit and put its facilities in DOT or other public
4490right-of-way. The DOT did not consider these important public policy and land
4502use considerations in proposing the defense and indemnification provisions of
4512paragraphs 12 and 15.
451665. The requirement that the utility defend any legal claims of DOT's
4528contractor due to delays caused by tube utility's failure to comply with the
4541approved schedule and the requirement that the utility indemnify DOT for DOT's
4553joint negligence will shift DOT expenses to the utility and cause the utility to
4567incur additional costs and expenses for use of DOT right-of-way.
457766. Utilities do not pass all of their operating costs on to the
4590ratepaying customers; shareholders bear the increase until, and unless, the
4600increase is favorably accepted by the Public Service Commission for inclusion as
4612a factor in the utility's rate structure.
461967. The utilities, in some instances, have no choice but to install their
4632facilities on the DOT right-of-way.
463768. Having utility facilities on DOT right-of-way is an efficient use of
4649land.
465069. The DOT is attempting to force provisions on the utilities through
4662rulemaking because the utilities will not voluntarily sign contracts which
4672contain the indemnification and defense provisions.
467870. The EIS prepared by DOT and incorporated in the June 16, 1989 edition
4692of the Florida Administrative Weekly states in pertinent part:
4701* * *
4704The following specific statements of economic
4710impact are provided as required by 120.54(2),
4717Florida Statutes:
4719* * *
4722(2) An estimate of the costs on the economic
4731benefit to all persons directly affected by
4738the proposed action:
4741Provisions presumed to have cost impact
4747on utilities include:
4750Utilities Liaison: Favorable cost impact
4755is anticipated from advance coordination
4760provisions of the rule chapter as amended.
4767Current reports indicate approximately 22
4772construction claims for $3.7 million relate
4778to utilities problems. A significant number
4784of these will be reduced or eliminated by
4792consistent liaison during the design process.
4798Maintenance of Traffic: Specific new
4803requirements for training of onsite
4808supervisors of Utilities Work Zones may
4814impact certain utilities who do not conduct
4821required training at present. This overhead
4827should be of such limited nature that it will
4836be offset by benefits such as improved
4843safety, reduced hazards, and lower costs of
4850accidents attributable to improperly
4854supervised traffic control in utility work
4860zones.
4861The Florida Utilities Coordinating
4865Committee has been materially involved in the
4872development process for these matters and has
4879provided continuous input to this revision of
4886the Utility Accommodation Guide.
489071. As stated in the EIS, the Florida Utilities Coordinating Committee
4901provided continuous input to the revision of the Utility Accommodation Guide; it
4913did not consider whether the "delay claims" provision should be added to
4925paragraph 12 or whether the "indemnification" provision should be added to
4936paragraph 15 of the new Utility Permit.
494372. The EIS prepared by DOT and incorporated in the June 16 edition of the
4958Florida Administrative Weekly is inaccurate and misleading in claiming
4967construction delays of $3.7 million are attributable to utilities.
497673. The DOT did not consider in the EIS the costs to the utilities of
4991defending "delay claims" filed by the road contractor.
499974. The DOT did not consider in the EIS that in shifting the cost of DOT's
5015joint negligence to the utility, DOT is imposing substantial costs on the
5027utility.
502875. The DOT did not consider that the indemnification amounts which the
5040utility would have to pay DOT for DOT's joint negligence could be in excess of
5055the $100,000-$200,000 allowed under the waiver of sovereign immunity statute,
5067Section 786.28, Florida Statutes (1989).
5072CONCLUSIONS OF LAW
507576. The Division of Administrative Hearings has jurisdiction over the
5085subject matter of this proceeding, and the parties thereto, pursuant to Sections
5097120.54(4) and 120.57(1), Florida Statutes.
510277. Each Petitioner in this proceeding has the burden to demonstrate that
5114it is a substantially affected person in order to have standing to seek an
5128administrative determination of the invalidity of any proposed rule on the
5139ground that the proposed rule is an invalid exercise of delegated legislative
5151authority. Section 120.54(4)(a), Florida Statutes (1989).
515778. A trade or professional association has standing to institute a rule
5169challenge proceeding even though it is acting solely as the representative of
5181its members. Florida Homebuilders Association v. Department of Labor and
5191Security, 412 So.2d 351 (Fla. 1982). The elements of associational standing
5202recognized by the Supreme Court in Florida Homebuilders are elements of proof,
5214which a trade or professional association must prove up at hearing in order to
5228demonstrate that the association has standing to institute a rule challenge
5239proceeding. At hearing, all parties stipulated that FNGA is substantially
5249affected by the challenged rule.
525479. Each of the Petitioners in this consolidated rule challenge matter has
5266met its burden and has standing to seek an administrative determination of the
5279invalidity of the proposed rules.
528480. Petitioners have the burden to demonstrate by the preponderance of the
5296evidence that the proposed rule constitutes an invalid exercise of delegated
5307legislative authority, as that phrase is defined in Section 120.52(8), Florida
5318Statutes (1989). Adam Smith Enterprises, Inc. v. Florida Department of
5328Environmental Regulation, 553 So.2d 1260, 1274, 14 FLW 2722, at footnote 23,
5340(Fla. 1st DCA 1989).
534481. The phrase "invalid exercise of delegated legislative authority" is
5354statutorily defined in Section 120.52(8), Florida Statutes, as follows:
5363(8) "Invalid exercise of delegated
5368legislative authority" means action which
5373goes beyond the powers, functions, and
5379duties delegated by the Legislature. A
5385proposed or existing rule is an invalid
5392exercise of delegated legislative authority
5397if any one or more of the following apply:
5406(a) The agency has materially failed
5412to follow the applicable rulemaking
5417procedures set forth in S. 120.54;
5423(b) The agency has exceeded its grant
5430of rulemaking authority, citation to
5435which is required by S. 120.54(7);
5441(c) The rule enlarges, modifies, or
5447contravenes the specific provisions
5451of law implemented, citation to which
5457is required by S. 120.54(7);
5462The rule is vague, fails to
5468establish adequate standards for
5472agency decisions, or vests unbridled
5477discretion in the agency; or
5482The rule is arbitrary or
5487capricious.
5488This subsection was added to the definitions section of Section 120.52 by
5500legislative act in 1988, and essentially codified judicial interpretation of the
5511term "invalid exercise of delegated legislative authority." See: Grove Isle,
5521Ltd. v. Department of Environmental Regulation, 454 So.2d 571, 573, 575 (Fla.
55331st DCA 1984); Department of Business Regulation v. Salvation Limited, Inc., 452
5545So.2d 65 (Fla. 1st DCA 1984).
555182. The Petitioners, by asserting the affirmative of the issues, have the
5563burden of proof which includes the ultimate burden of persuasion. Florida
5574Department of Transportation v. J.W.C. Co., Inc., 396 So.2d 778 (Fla. 1st DCA
55871981).
558883. In Department of Professional Regulation, Board of Medical Examiners
5598v. Durrani, 455 So.2d 515 at 517 (Fla. 1st DCA 1984), the court stated:
5612The well recognized general rule is that
5619agencies are to be accorded wide discretion
5626in the exercise of their lawful rulemaking
5633authority, clearly conferred or fairly
5638implied and consistent with the agencies'
5644general statutory duties . . . An
5651construction of the statute it administers
5657is entitled to great weight and is not to be
5667overturned unless clearly erroneous .
5672Moreover, the agency's interpretation of a
5678statute need not be the sole possible
5685interpretation or even the most desirable
5691one; it need only be within the range of
5700possible interpretations . .
5704It is not this tribunal's function to say if the Department's interpretation is
5717preferable; this tribunal is concerned only if the proposed rule is within the
5730range of permissible construction that comports with and effectuates discerned
5740legislative intent. Florida League of Cities v. Department of Insurance, 540
5751So.2d 850, 857-858 (Fla. 1st DCA 1989); Department of Administration v. Nelson,
5763424 So.2d 852 (Fla. 1st DCA 1982)
577084. Petitioners' attack on the propriety and constitutionality of the
5780rules on grounds that they are an impairment of contract under Section 10, of
5794the Florida Constitution, are more appropriately dealt with by another forum,
5805since they are not invalid on their face. Department of Administration,
5816Division of Personnel v. Department of Administration, Division of
5825Administrative Hearing, 326 So.2d 187 (Fla. 1st DCA 1976); Department of Revenue
5837v. Young American Builders, 330 So.2d 864 (Fla. 1st DCA 1976); Smith v. Willis,
5851415 So.2d 1331 (Fla. 1st DCA 1982).
585885. The DOT has followed the rulemaking procedure, as set forth in Section
5871120.54, Florida Statutes, in every material way. DOT gave proper notice, and
5883followed the correct procedure for incorporating by reference the permit
5893provisions in the proposed amendments to Rule 14-46.01, Florida Administrative
5903Code. Section 120.52(8)(a), Florida Statutes (1989)
590986. The DOT cites as specific authority in support of the proposed rules
5922Sections 120.53(l) and 334.044(2), Florida Statutes, and, as the law
5932implemented, cites Sections 337.401, 337.403, 337.404 and 339.05, Florida
5941Statutes. These provisions provide in pertinent part:
5948334.044 Powers and duties of department.--
5954The Department shall have the following
5960general powers and duties:
5964(2) To adopt rules, procedures, and
5970standards for the conduct of its business
5977operations and the implementation of any
5983provision of law for which the department is
5991responsible.
5992* * *
5995337.401 Use of right-of-way for utilities
6001subject to regulation; permit; fees.--
6006(1) The department and local governmental
6012entities, referred to in ss. 337.401-337.404
6018as the "authority," that have jurisdiction
6024and control of public roads are authorized to
6032prescribe and enforce reasonable rules or
6038regulations with reference to the placing and
6045maintaining along, across, or on any road
6052under their respective jurisdictions any
6057electric transmission, telephone, or
6061telegraph lines; pole lines; poles; railways;
6067ditches; sewers; water, heat, or gas mains;
6074pipelines; fences; gasoline tanks and pumps;
6080or other structures hereinafter referred to
6086as the "utility."
6089(2) The authority may grant to any person
6097who is a resident of this state,. or to any
6108corporation which is organized under the laws
6115of this state or licensed to do business
6123within this state, the use of a right-of-way
6131for the utility in accordance with such rules
6139or regulations as the authority may adopt.
6146No utility shall be installed, located, or
6153relocated unless authorized by a written
6159permit issued by the authority. The permit
6166shall require the permitholder to be
6172responsible for any damage resulting from the
6179issuance of such permit. The authority may
6186initiate injunctive proceedings as provided
6191in S. 120.69 to enforce provisions of this
6199subsection or any rule or order issued or
6207entered into pursuant thereto.
6211337.403 Relocation of utility; expenses.--
6216(1) Any utility heretofore or hereafter
6222placed upon, under, over, or alone any public
6230road that is found by the authority to be
6239unreasonably interfering in any way with the
6246convenient, safe, or continuous use, or the
6253maintenance, improvement, extension, or
6257expansion, of such public road shall, upon 30
6265days written notice to the utility or its
6273agent by the authority, be removed or
6280relocated by such utility at its own expense
6288except as provided in paragraphs (a) and (b).
6296(a) If the relocation of utility facilities,
6303as referred to in S. 111 of the Federal-Aid
6312Highway Act of 1956, Pub.L.No. 627 of the
6320Eighty-Fourth Congress, is necessitated by
6325the construction of a project on the federal-
6333aid interstate system, including extensions
6338thereof within urban areas, and the cost of
6346such project is eligible and approved for
6353reimbursement by the Federal Government to
6359the extent of 90 percent or more under the
6368Federal Aid Highway Act, or any amendment
6375thereof, then in that event the utility
6382owning or operating such facilities shall
6388relocate such facilities upon order of the
6395department, and the state shall pay the
6402entire expense properly attributable to such
6408relocation after deducting therefrom any
6413increase in the value of the new facility and
6422any salvage value derived from the old
6429facility.
6430(b) When a joint agreement between the
6437department and the utility is executed for
6444utility improvement, relocation, or removal
6449work to be accomplished as part of a contract
6458for construction of a
6462facility, the department may participate in
6468those utility improvement, relocation, or
6473removal costs that exceed the departments
6479official estimate of the cost of such work by
6488more than 10 percent. The amount of such
6496participation shall be limited to the
6502difference between the official estimate of
6508all the work in the joint agreement plus 10
6517percent and the amount awarded for this work
6525in the construction contract for such work.
6532The department may not participate in any
6539utility improvement, relocation, or removal
6544costs that occur as a result of changes or
6553additions during the course of the contract.
6560(2) If such removal or relocation is
6567incidental to work to be done on such road,
6576the notice shall be given at the same time
6585the contract for the work is advertised for
6593bids, or 30 days prior to the commencement of
6602such work by the authority.
6607(3) Whenever an order of the authority
6614requires such removal or change in the
6621location of any utility from the right-of-way
6628of a public road, and the owner thereof fails
6637to remove or change the same at; his own
6646expense to conform to the order within the
6654time stated in the notice, the authority
6661shall proceed to cause the utility to be
6669removed. The expense thereby incurred shall
6675be paid out of any money available therefore,
6683and such expense shall, except as provided in
6691subsection (1), be charged against the owner
6698and levied and collected and paid into the
6706fund from which the expense of such
6713relocation as paid.
6716337.404 Removal or relocation of utility
6722facilities; notice and order; court review--
6728(1) Whenever it shall become necessary for
6735the authority to remove or relocate any
6742utility as provided in the preceding section,
6749the owner of the utility, or his chief agent,
6758shall be given notice of such removal or
6766relocation and an order requiring the payment
6773of the cost thereof, and shall be given
6781reasonable time, which shall not be less than
678920 or more than 30 days, in which to appear
6799before the authority to contest the
6805reasonableness of the order. Should the
6811owner or his representative not appear, the
6818determination of the cost to the owner shall
6826be final. Authorities considered
6830for the purposes of chapter 120 shall
6837adjudicate removal or relocation of utilities
6843pursuant to chapter 120.
6847(2) A final order of the authority shall
6855constitute a lien on any property of the
6863owner and may be enforced by filing an
6871authenticated copy of the order in the office
6879of the clerk of the circuit court of the
6888county wherein the owner's property is
6894located.
6895(3) The owner may obtain judicial review of
6903the final order of the authority within the
6911time and in the manner provided by the
6919Florida Rules of Appellate Procedure by
6925filing in the circuit court of the county in
6934which the utility was relocated a petition
6941for a writ of certiorari in the manner
6949prescribed by said rules or in the manner
6957provided by chapter 120 when the respondent
6964is an agency for purposes of chapter 120.
6972339.05 Assent to federal aid given.--The
6978state hereby assents to the provisions of the
6986Act of Congress approved July 11, 1916, known
6994as the Federal Aid Law, which Act of
7002is entitled "An act to provide that the
7010United States shall aid the states in the
7018construction of rural post roads and for
7025other purposes," and assents to all
7031subsequent amendments to such Act of Congress
7038and any other act heretofore passed or that
7046may be hereafter passed providing for federal
7053aid to the states for the construction of
7061highways and other related projects. The
7067department is authorized to make application
7073for the advancement of federal funds and to
7081make all contracts and do all things
7088necessary to cooperate with the United States
7095Government in the construction of roads under
7102the provisions of such Acts of Congress and
7110all amendments thereto.
7113A. Rule 14-46.0011
711687. The DOT's proposed Rule 14-46.0011 concerning DOT's liaison with
7126utilities is a statement of general policy, and is a reasonable rule authorized
7139by Sections 334.044(2), 337.401, 337.403, 337.404 and 337.405, Florida Statutes
7149These statutes are correctly cited by DOT in support of this proposed rule. On
7163its face, this proposed rule does not offend any of the provisions of Sections
7177120.52(8) or 120.54(4), Florida Statutes, and, therefore, does not constitute an
7188invalid exercise of delegated legislative authority. As a statement of general
7199policy it is not vague. Since no decisions affecting substantial interest are
7211intended under this proposed rule, the rule need not specify any standards for
7224agency decisions. Since the rule directs DOT to coordinate with utilities in
7236planning its highway projects, the rule does not vest unbridled discretion in
7248DOT.
7249B. Rule 14-46.001 - Utility Permit, Paragraph 12
725788. Proposed paragraph 12 of the Utility Permit provides:
726612. It is agreed that in the event the
7275relocation of said utility facilities are
7281scheduled to be done simultaneously with the
7288Department's construction work, the permitee
7293will coordinate with the Department before
7299proceeding, shall cooperate with the
7304Department's contractor to arrange the
7309sequence of work so as not to unnecessarily
7317delay the work of the Department's
7323contractor, defend any legal claims of the
7330Department's contractor due to delays caused
7336by the permittee's failure to comply with the
7344approved schedule, and shall comply with all
7351provisions of the law and Rule 14-46, Florida
7359Administrative Code. The Permittee shall not
7365be responsible for delays beyond its normal
7372control.
737389. The DOT cites in support of the proposed rule, in particular, Sections
7386334.044(2), 337.401, 337.403, 337.404 and 339.05, Florida Statutes. This
7395statutory scheme authorizes DOT to make and enforce reasonable rules with which
7407utilities must comply before receiving a permit to be accommodated on the DOT
7420right-of-way. The DOT's mission under the State Transportation Code is to plan,
7432construct and maintain transportation facilities. Section 334.404(13), Florida
7440Statutes (1989). The accommodation of utilities by permit is subject to
7451compliance by utilities with reasonable DOT rules. Section 337.401(1), Florida
7461Statutes (1989), authorizes DOT to "prescribe and enforce reasonable rules or
7472regulations" with reference to the accommodation of utilities on roads within
7483DOT's jurisdiction. While Section 337.401(2), Florida Statutes, states, in
7492pertinent part:
7494(2) . . . No utility shall be installed,
7503located or relocated unless authorized by a
7510written permit issued by the authority. The
7517permit shall require the permitholder to be
7524responsible for any damage resulting from
7530the issuance of such permit.
753590. It is clear that a statutory condition of the permit requires that the
7549utility shall be responsible for any damage resulting from the issuance of a
7562permit [Section 337.401(2)], and also, the utility must, at its own expense,
7574restore any public road which it damages or impairs in any way because of the
7589installation, inspection or repair of its facilities located on the road. The
7601DOT may charge the cost of such restoration to the utility if the utility fails
7616to act. Section 337.402, Florida Statutes.
762291. Under this statutory scheme, the right of utilities, including
7632whatever rights are provided telephone companies under Section 362.01, Florida
7642Statutes (1987), are subordinate to DOT and the rights of the traveling public
7655to the use of the public roads of this state.
766592. The DOT argues that it is requiring the utility to bear the burden of
7680defense only for claims which DOT would not have had but for the utility's
7694failure to follow its schedule, and only if the failure was within the utility's
7708control. This is a reasonable interpretation of the statutory requirement that
7719a permitholder shall be responsible for "any damage resulting from the issuance
7731of such permit." Section 337.401(2), Florida Statutes.
773893. The DOT has a problem with the mechanics of implementing paragraph 12.
7751The DOT cannot explain which utility would defend the DOT if more than one
7765utility is involved, a frequent occurrence. The DOT testified that the
7776utilities' duty to defend did not extend to "delays beyond its normal control,"
7789and that "normal control" is construed to mean a precondition of the defense
7802duty. "Normal control" could be interpreted in different ways even if
7813guidelines were established. The DOT admitted that there could be litigation
7824over the term "normal control." However, the sentence is not so vague that a
7838person of common intelligence cannot say with certainty from the terms of such
7851rule or statute what is required. See: D'Alemberte v. Anderson, 349 So.2d 164
7864(Fla. 1977).
786694. The DOT put the defense provision in the Permit to force such
7879provisions upon the utility without its consent, because they would not
7890voluntarily consent to the provision during contract negotiations.
789895. The DOT wants this provision: (l) to enforce the provision that
7910utilities will do what they are supposed to do to keep a contractor from being
7925delayed in relocation work; and (2) to give the DOT an additional remedy, a
"7939clout of enforcement," with respect to relocations whereby the DOT could revoke
7951the utility permit in the event of noncompliance. The DOT's intent is to force
7965the provisions through rulemaking into the Permit; then, by the fact the
7977provisions are in the Permit, to require the same type of language be included
7991in a relocation contract.
799596. The utility permit is issued when the utility installs its facilities
8007on the DOT right-of-way; a separate agreement controls relocations. A DOT
8018permit )S only to a utility's facilities that are located on the DOT right-of-
8032way and not to those facilities located in public right-of-way owned by other
8045government agencies, platted utility easements or private easements. Any of
8055these facilities -- to which the Permit does not apply -- could be relocated as
8070the result of a DOT construction project.
807797. The DOT Quality Improvement Team, after studying delay claims,
8087determined the primary root cause of the problems were outdated and inadequate
8099DOT procedures. The recommended solutions to help reduce utility delays did not
8111include the defense and indemnification provisions contained in proposed
8120paragraphs 12 and 15 of the Permit.
812798. The DOT did not consider all relevant facts. The DOT looked at only
8141three things in considering the impact of the proposed rule. The conclusion
8153that the proposed rule would result in a $2 million saving due to reduction in
8168utility delays is an estimate only. The DOT did not consider settlement amounts
8181or the fact that the majority of delay claims were associated with water and
8195sewer relocation. The DOT made no effort to break the claims down into type of
8210utilities and, even though it is not surprised that the majority of claims
8223involved water and sewer facilities, doesn't know why that should be so.
823599. It is the DOT and the DOT's contractor who are responsible for
8248coordinating the various utility schedules and the construction work into one
8259project schedule. The DOT contractor submits this project schedule to the DOT
8271and the DOT project engineer and the district construction engineer review that
8283schedule and have authority to disapprove that schedule. It is not this project
8296schedule, however, but the "approved" utility schedule of the individual utility
8307which gives rise to the utility's duty to defend the DOT against the claims of
8322the DOT's contractor in paragraph 12 of the Permit This approved schedule is
8335prepared at the time that the utility has no knowledge of how the contractor
8349wants to proceed on the job --. the contractor may have a different approach to
8364constructing the job which could result in the utility changing their plane as
8377to where they planned to start work.
8384100. The requirement of a pre-construction conference and a project
8394schedule was implemented by the DOT only toward the end of 1987, when DOT's
8408standard form contract was amended to include scheduling requirements on the
8419part of the contractor. It is too early, and there is no data yet available, to
8435tell whether this new procedure will be effective, as it is anticipated to be,
8449in helping to reduce delays caused by utility relocations.
8458101. Further, the DOT in proposing paragraph 12 did not reasonably
8469consider the fact that the utility is not a party to the construction contract
8483between DOT and the DOT contractor. The utility has no control over the terms
8497and conditions of that contract, including the ability of the DOT contractor to
8510sue the DOT for delay claims. When the DOT contractor sues because of a utility
8525delay, it sues the DOT based on its construction contract with the DOT and may
8540allege the DOT's failure to coordinate the relocation efforts of the utility
8552owners constituted a breach of the Contract. DOT may then join the utility as a
8567third party.
8569102. Although it may not be wise or efficient, it is not arbitrary to
8583force a utility as a condition of right-of-way use to defend the DOT against
8597DOT's own contractors, when the delay claim is allegedly due to delays caused by
8611the utility's failure to comply with the approved schedule.
8620103. The preponderance of evidence is that the phrase
"8629. . . defend any legal claims of the Department's contractor due to delays
8643caused by the permittee's failure to comply with the approved schedule . . . "
8657within DOT's proposed paragraph 12 of the new Utility Permit is not an invalid
8671exercise of delegated legislative authority, as defined in Section 120.52(8),
8681Florida Statutes.
8683C. Paragraph 15 of the Utility Permit Indemnification of DOT's Joint
8694Negligence
8695104. The proposed paragraph 15 of the Utility Permit, which is a part of
8709the Utility Accommodations Guide (UAG), is incorporated by reference into Rule
872014-46.001. By its terms, the "except [for the] . . . sole negligence"
8733provision requires the utility to pay for the joint negligence of the DOT as a
8748condition of use of the DOT right-of-way.
8755105. Under the provisions of Section 337.401, Florida Statutes, DOT can
8766require the utility to be responsible for any damage resulting from the issuance
8779of a permit. Under the existing provisions of paragraph 15 of the Utility
8792Permit, utilities are required to indemnify, defend, and save harmless the DOT
8804from all loss, damage, cost or expense arising from the permit. The proposed
8817new paragraph 15 provision which requires indemnification, except for DOT's sole
8828negligence is an extension of that provision. Paragraph 12 of the existing
8840standard form Master Agreements, previously executed by Petitioners, requires
8849utilities to defend against contractor delay claims due to delays caused by the
8862utilities' negligence that were not beyond its control. The new permit requires
8874the utility to defend DOT from any delay claims caused by the utility's failure
8888to comply with its approved work schedule other than for delays beyond the
8901utility's normal control, and indemnify DOT for any claim, loss, damage, cost,
8913charge or expense except for damages resulting from the sole negligence of the
8926DOT.
8927106. Under proposed paragraph 15, if there was a judgment finding that the
8940DOT was 99% negligent and the utility was 1% negligent, the utility would have
8954to pay the entire judgment. Under the general law relating to comparative fault
8967and contribution among tort-feasors, the utility would have a judgment entered
8978against it and, therefore, have to pay for only 1% of that liability -- the part
8994directly attributed to the utility's own fault. Paragraph 15 of the Utility
9006Permit modifies Florida negligence law, Section 768.81, Florida Statutes, and
9016enlarges, modifies or contravenes the specific provisions of Section 337.401(2),
9026Florida Statutes, permitting the DOT to hold the utility responsible for any
9038damage that the utility causes. State Board of Optometry v. Florida Society of
9051Ophthalmology, 539 So.2d 878. As the court stated at p. 885
9062We recognize that in [Department of
9068Professional Regulation, Board of Medicine v.
9074Durrani, 455 So.2d 515 (Fla. 1st DCA 1984] we
9083indicated that the court must approve the
9090agency's selection of any possible
9095interpretation of the enabling statute. But
9101in so stating, we did not mean that any
9110conceivable construction of a statute must be
9117approved irrespective of how strained or
9123ingeniously reliant or implied authority is
9129might be; rather, as made clear in the cases
9138cited in Durrani in support of the stated
9146proposition, only a permissible construction
9151by the agency that comports with and
9158effectuates discerned legislative intent will
9163be sustained by the court. (citations
9169omitted)."
9170DOT's interpretation of the statute goes beyond the permissible construction
9180that can be given to the statute and is an invalid exercise of delegated
9194legislative authority.
9196107. The DOT found it necessary to put the indemnification provision in
9208the Permit because the utilities would not sign a contract with that language in
9222the contract. Because Florida law views indemnification of another for that
9233other's own negligence with disfavor, it allows such indemnification only in
9244contracts freely entered into, provided that the indemnification is expressed in
9255clear and unequivocal terms. See: Charles Poe Masonry, Inc. v. Spring
9266Scaffolding Rental Equipment Company,
9270108. The DOT strongly relies on the case of Mitchell Maintenance Systems
9282v. State, Department of Transportation, 442 So.2d 276 (Fla. 4th DCA 1983), in
9295its justification for implementing paragraph 15. The sole issue decided by the
9307court in Mitchell, supra, is that the indemnification language identical to the
9319language which DOT proposes for paragraph 15 of the Permit is clear and
9332unequivocal. However, the Mitchell case is limited by its facts to a contract
9345situation. It is limited to a contract willingly entered into by a private
9358individual who wished to perform maintenance work on DOT utility poles. Mitchell
9370does not involve rulemaking, does not involve public utility use of right-of-way
9382and does not involve the public policy issues of providing economic utility
9394service or land use discussed above.
9400109. Further, unlike the situation in Mitchell where the maintenance work
9411is completely under the control of the party agreeing to indemnify the DOT with
9425respect to any damage arising out of that maintenance work, the control on the
9439right-of-way situation is with the DOT or third persons. The road construction
9451and maintenance of the road is under the control and is the responsibility of
9465DOT. The DOT's use of the Mitchell case, as justification for shifting the cost
9479of the DOT's joint negligence to the utility through rulemaking is not legal
9492authorization for requiring the utility to pay for DOT's joint negligence.
9503110. Prior to the adoption of any rule, Section 120.54(2)(b), Florida
9514Statutes, mandates that an agency prepare an economic impact statement (EIS) to
9526promote agency introspection in administrative rulemaking; to ensure a
9535comprehensive and accurate analysis of economic factors which work with social
9546and legislative goals to facilitate informed decision making and to expose the
9558administrative rulemaking process to public scrutiny. Florida-Texas Freight,
9566Inc. v. Hawkins, 379 So.2d 933, at 946 (Fla. 1979). In Dept. of Health &
9581Rehabilitative Services v. Wright, 439 So.2d 937 (Fla. 1st DCA 1983), the court
9594held that an economic impact statement which insufficiently addressed the
9604potentially substantial economic repercussions of a proposed rule change was
9614invalid and, hence, the rule was an invalid exercise of delegated legislative
9626authority. The court said:
9630. . .materiality of the economic impact
9637statement to the rulemaking process cannot be
9644given short shrift. Preparation of the
9650statement is a sobering task, one designed to
9658arrest agency discretion bordering on the
9664despotic, and to channel it through logic and
9672reason to a rational end. Id. at 641
9680111. The EIS prepared by DOT and incorporated in the June 16 edition of
9694the Florida Administrative Weekly is inaccurate and misleading in claiming that
9705construction delays of $3.7 million are attributable to utilities. The costs of
9717claims for delays related to utilities' problems are insignificant overall and
9728cannot serve as a reasonable basis for adoption of the proposed rules.
9740112. A public utility has a general requirement under Section 366.03,
9751Florida Statutes (1989), to provide the public with adequate and economical
9762utility installations and services. The DOT did not consider the fact in the EIS
9776that in shifting the cost of DOT's joint negligence to the utility, DOT is
9790imposing substantial costs on the utility and is, in fact., increasing those
9802costs by an unquantifiable amount. These additional costs can have a negative
9814impact on the utility's ability to provide economical service.
9823113. The DOT did not consider that the indemnification amounts which the
9835utility would have to pay DOT foil DOT's joint negligence could be in excess of
9850the $100,000 - $200,000 allowed under the waiver of sovereign immunity statute,
9864Section 786.28, Florida Statutes (1989).
9869114. The EIS discussing the costs and benefits of the proposed rule
9881change, completely ignores the cost of requiring utilities to assume all of
9893DOT's tort and contract liability, except where the Department is solely
9904negligent.
9905Section 120.54(2), Florida Statutes (1989), provides that an agency's
9914failure to include within its rule an "adequate" statement of economic impact is
9927grounds for invalidation of the rule. The Florida Supreme Court has observed
9939that the procedure envisioned by this section does not "command adherence to
9951form over substance," Florida-Texas Freight, supra, and that provision does not
9962require perfection but only "substantial compliance" with Section 120.57(2)(b),
9971Florida Statutes (1989). In the matter before this tribunal, DOT gave no
9983consideration at all to the economic impact of shifting liability from the
9995Department to the utility and ultimately the utility's ratepayers. This section
10006of the rule could be devastating economically to the utility permitholder and,
10018therefore, the Department's reasoning for its adoption is not supported by law
10030or logic and is invalid. Department of Health and Rehabilitative Services v.
10042Wright, 439 So.2d 937 (Fla. 1st DCA 1983).
10050115. Paragraph 15 of the Utility Permit enlarges, modifies or contravenes
10061the law implemented, and the EIS is not adequate as pertains to this section and
10076is, therefore, an invalid exercise of delegated legislative authority under
10086Sections 120.52(8)(c) and 120.54(2)(b), Florida Statutes (1989). Therefore,
10094based on the foregoing findings of fact and conclusions of law it is
10107ORDERED, as follows:
101101. Proposed Rule 14-46.0011 is not an invalid exercise of delegated
10121legislative authority;
101232. Proposed Rule 14-46.001 and the Utility Accommodation Guide, adopted by
10134reference therein, Which includes a new form Utility Permit, are not an invalid
10147exercise of delegated legislative authority, except for Paragraph 15 of the
10158Utility Permit, contained within the UAG and adopted by reference in proposed
10170Rule 14-46.001, which is held to be invalid. Section 120.52(8)(c) and
10181120.54(2)(b), Florida Statutes (198).
101853. Except for the issues abated (see: Preliminary Statement), all other
10196issues are dismissed, and the Department of Transportation is free to conclude
10208its rule promulgation of the rules and Utility Accommodation Guide.
10218Jurisdiction of the abated issues are remanded to the Department of
10229Transportation for resolution through formally announced and noticed changes to
10239the proposed rules.
10242DONE and ORDERED this 8th day of March, 1990, in Tallahassee, Leon County,
10255Florida.
10256__________________________
10257DANIEL M. KILBRIDE
10260Hearing Officer
10262Division of Administrative Hearings
10266The DeSoto Building
102691230 Apalachee Parkway
10272Tallahassee, Florida 32399-1550
10275(904) 488-9675
10277Filed with the Clerk of the
10283Division of Administrative Hearings
10287this 9th day of March, 1990.
10293APPENDIX
10294The following constitutes my specific rulings, in accordance with section
10304120.59, Florida Statutes, on findings of fact submitted by the parties.
10315Proposed Findings of Fact - GTE Florida Inc.
10323Accepted: Paragraphs 1, 2, 4, 5 (impart) , 6, 7, 8 (in substance) 9, 10, 13,
1033814, 15
10340Rejected: Against weight: 3, 5 (in part) Argument: 11, 12
10350Proposed Findings of Fact-Florida Power and Light Co.
10358Accepted 1, 2 (in substance), 3, 6, 7, 8, 9, 10, 11, 12, 13, 15, 16, 17, 18, 19,
1037720, 21, 23, 24, 25 (in substance), 26, 27, 28 (in substance), 29, 31
10391Rejected: - Against greater weight of the evidence: 4, 5
10401- Subservient: 14
10404- conclusions of law: 22, 30, 32
10411Proposed Findings of Fact - Southern Bell Telephone and Telegraph Co.
10422Accepted: 1, 2, 4, 5, 6, 7, 10 (in substance), 12 (in substance) Rejected:
10436Resolved in the Preliminary Statement: 3
10442- conclusion of law: 8, 9, 13, 14, 17
10451- not supported by the greater weight of the
10460evidence: 11, 15, 16
10464Proposed Findings of Fact - Department of Transportation
10472Accepted: (as stated or in substance): 10, 11, 12, 13, 15, 16, 17, 18, 19, 20,
1048821 (in part), 22, 23, 24, 25, 26, 27, 28, 29, 30, 31, 32, 33, 34, 35 36, (in
10507part), 42, 46, 47, 48, 49, 50, 51, 55(in part), 57, 60, 62, 63, 64, 65, 68, 69,
1052570, 71, 72, 75, 77, 82, 84, 87, 88
10534Rejected as resolved in the Preliminary Statement: 1, 2, 3, 4, 5, 6, 7, 8, 9,
1055014
10551Rejected as irrelevant or subservient: 58, 79, 80, 81, 85, 94
10562Rejected as argument: 44, 45, 54, 56, 61, 66, 67, 73, 74, 78, 83, 90, 91, 95,
1057996, 91
10581Rejected as not supported by the greater weight of the evidence: 21 ( in part),
1059637, 38, 39, 40, 41, 43, 52, 53, 55 (in part), 59, 76, 85, 86, 87
10612COPIES FURNISHED:
10614Robert P. Daniti, Esquire Ben G. Watts, Esquire
10622Senior Litigation Attorney Secretary
10626Department of Transportation Department of Transportation
10632605 Suwannee Street 605 Suwannee Street
10638Tallahassee, FL 32399-0458 Tallahassee, Fl 32399-0458
10644Attn: Eleanor Turner, MS 58
10649Lorin H. Albeck, Esquire
10653General Attorney Thomas H. Bateman, III
10659GTE Florida Incorporated General Counsel
10664Post Office Box 110, Mail Code 7 Department of Transportation
10674Tampa, FL 33601-0110 562 Haydon Burns Building
10681Tallahassee, FL 32399-0458
10684Jean G. Howard, Esquire
10688Law Department
10690Florida Power and Light Company
10695Post Office Box 029100
10699Miami, FL 33102
10702Robert G. Beatty, Esquire
10706Southern Bell Telephone
10709Legal Department
10711Museum Tower, Suite 1910
10715150 West Flagler Street
10719Miami, FL 33130
10722Kay L. Wolf, Esquire
10726Assistant Vice President-
10729Law
10730United Telephone Company
10733of Florida
10735Post Office Box 5000
10739Altamonte Springs, FL 32716-5000
10743Richard Brightman, Esquire
10746Post Office Box 6526
10750Tallahassee, FL 32314
10753NOTICE OF RIGHT TO JUDICIAL REVIEW
10759A PARTY WHO IS ADVERSELY AFFECTED BY THIS FINAL ORDER IS ENTITLED TO JUDICIAL
10773REVIEW PURSUANT TO SECTION 102.68, FLORIDA STATUTES. REVIEW PROCEEDINGS ARE
10783GOVERNED BY THE FLORIDA RULES OF APPELLATE PROCEDURE. SUCH PROCEEDINGS ARE
10794COMMENCED BY FILING ONE COPY OF A NOTICE OF APPEAL WITH THE AGENCY CLERK OF THE
10810DIVISION OF ADMINISTRATIVE HEARINGS AND A SECOND COPY, ACCOMPANIED BY FILING
10821FEES PRESCRIBED BY LAW, WITH THE DISTRICT COURT OF APPEAL, FIRST DISTRICT, OR
10834WITH THE DISTRICT COURT OF APPEAL IN THE APPELLATE DISTRICT WHERE THE PARTY
10847RESIDES. THE NOTICE OF APPEAL MUST BE FILED WITHIN 30 DAYS OF RENDITION OF THE
10862ORDER TO BE REVIEWED.
Case Information
- Judge:
- DANIEL M. KILBRIDE
- Date Filed:
- 06/26/1989
- Date Assignment:
- 07/24/1989
- Last Docket Entry:
- 03/08/1990
- Location:
- Tallahassee, Florida
- District:
- Northern
- Agency:
- Department of Transportation
- Suffix:
- RP